Terms and Conditions

1. Introduction

About Fence Company Concord NC

Welcome to Fence Company Concord NC, your premier destination for high-quality fencing services. This document outlines the terms and conditions governing our services and website use. By engaging with us, you agree to adhere to these terms. Please carefully review the following information.

Services Offered

Fencing Solutions

We take pride in offering a diverse range of fencing solutions tailored to your specific needs. Our services encompass professional installation and repair of various types of fences.

Contact Information

• Address: 110 Long Ave NE, Concord, NC 28025, USA
• Phone: +1 (704) 397-3389
• Website: https://fencecompanyconcordnc.com/

Quotations and Payments

Requesting Quotations

To initiate a quotation for your project, please contact our dedicated team. Quotations provided are valid for a period of 30 days from the date of issuance.

Payment Terms

Payment for our services is due upon the successful completion of the project. We accept various payment methods, including cash, checks, and electronic payments. Timely payment is crucial to ensure a smooth and efficient process.

Project Scheduling and Delays

Project Timelines

While we strive for transparency and efficiency in project timelines, it’s important to note that these are estimates. Unforeseen circumstances, such as weather conditions, may impact the completion date.

Delays and Unforeseen Events

Fence Company Concord NC holds no liability for delays caused by factors beyond our control, including but not limited to adverse weather conditions, material shortages, or acts of nature.

Warranty Information

Installation Warranty

We stand behind the quality of our work. Our standard warranty for installations covers a period of one year, ensuring the durability of our craftsmanship and materials.

Repair Warranty

For repair services, we offer a warranty period of 90 days, assuring the quality and longevity of the repair work undertaken.

Maintenance Guidelines

Customer Responsibilities

Customers are responsible for the regular maintenance of their fences. Neglecting maintenance may void the warranty provided by Fence Company Concord NC. Regular care ensures the longevity and aesthetic appeal of your fencing.

Optional Maintenance Services

For added convenience, we offer optional maintenance services at an additional cost. Feel free to inquire with our team for details on these services, designed to keep your fence in optimal condition.

Website Usage

Information Accuracy

While we strive to maintain accurate and up-to-date information on our website, Fence Company Concord NC cannot guarantee the absence of inaccuracies or omissions. We appreciate your understanding in this regard.

Third-Party Links

Our website may contain links to third-party websites for additional information or resources. We do not assume responsibility for the content or practices of these external sites.

Privacy Policy

Data Collection

We collect and process personal information in accordance with our Privacy Policy, available on our website. By engaging with our services, you consent to the collection and use of your data as outlined in this policy.

Security Measures

Fence Company Concord NC employs industry-standard security measures to protect your personal information. However, it’s important to note that no online transmission is entirely secure.

Dispute Resolution

Mediation Process

In the event of a dispute, both parties agree to engage in mediation before considering legal action. Mediation provides an opportunity for a fair and mutually agreeable resolution.

Legal Action

If mediation proves unsuccessful, any legal action must be brought before the courts in the state of North Carolina, where Fence Company Concord NC is based.

Amendments to Terms

Changes to Terms

Fence Company Concord NC reserves the right to modify these Terms and Conditions at any time. Changes become effective upon posting on our website.

Notification of Changes

Clients will be promptly notified of significant changes to the Terms and Conditions. It is the responsibility of the client to stay informed about any updates.

Conclusion

By engaging with Fence Company Concord NC, you acknowledge and agree to abide by these Terms and Conditions. If you have any questions or concerns, please don’t hesitate to contact us using the provided contact details.